|
Bond#: 929592044
<br /> Premium : included in pert bond
<br /> PAYMENT BOND
<br /> KNOW ALL MEN BY THESE PRESENTS: That we, Granite Rock Company
<br /> as Principal, and, Western Surety Company organized and
<br /> existing under the laws of the State of cu
<br /> South Dakota , and authorized to execute
<br /> bonds and undertaking as sole surety, as Surety, are held and firmly bound unto any and all
<br /> persons named in California Civil Code Section 3181 whose claim has not been paid by the
<br /> Contractor, company or corporation in the aggregate total of
<br /> One Million Three Hundred Seventy Thousand Two Hundred Dollars ($ 1,370,273.48 ) (being
<br /> 100% of the Contract amount)for the payment whereof, well and truly to be made, said Principal
<br /> and Surety bond themselves, their heirs, administrators, successors, and assigns, jointly and
<br /> severally, firmly by these presents. "Seventy Three&48/100
<br /> THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that, whereas the above with
<br /> the City of Redwood City ("City")to do the following work, to-wit:
<br /> 2013-2014 ASHPALT RUBER CHIP SEAL AND SPOT REPAIR PROJECT
<br /> NOW, THEREFORE, if the above-bounden Principal or his subcontractors fail to pay any of the
<br /> persons named in Section 3181 of the Civil Code of the State of California, or amounts due under
<br /> the Unemployment Insurance Code with respect to work or labor performed under the Contract,
<br /> or for any amounts required to be deducted, withheld, and paid over to the Employment
<br /> Development Department from the wages of employees of the Contractor and his subcontractor
<br /> pursuant to Section 13020 of the Unemployment Insurance Code of the State of California, with
<br /> respect to such work and labor,the surety will pay for the same, in the amount not exceeding the
<br /> sum speed in this bond, and also, in case suit is brought upon this bond, a reasonable
<br /> attorney's fee, to be fixed by the Court.
<br /> This bond shall inure to the benefit of any person named in Section 3181 of the Civil Code of the
<br /> State of California so as to give a right of action to them or their assignees in suit brought upon
<br /> this bond.
<br /> This bond is executed and filed to comply with the provisions of the act of the Legislature of the
<br /> State of California as designated in Civil Code Sections 3247-3252, inclusive, and all
<br /> amendments thereto.
<br /> And the said Surety, for value received, hereby stipulates and agrees to waive the provisions of
<br /> California Civil Code Section 2819 regarding consent to change, extension of time alteration, or
<br /> addition to the terms of the Contract, or to the work to be performed thereunder, or the
<br /> Specifications accompanying the same, shall in any way affect its obligations on this bond; and it
<br /> does hereby waive notice of any such change, extension of time, alteration, or addition to the
<br /> terms of the Contract, or to the work, or to the Specifications.
<br /> IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their
<br /> seals this 15th day of September 12014 the name and corporate seal of
<br /> 2013-2014 ASPHALT RUBBER CHIP SEAL AND SPOT REPAIR PROJECT
<br />
|