RecDoc 2015-052074 - Laserfiche WebLink

Browse Search

Exhibit C FORM OF PAYMENT BOND (SUBDIVISION) KNOW ALL MEN BY THESE PRESENTS: the City of Redwood City (°City"), County of San Mateo, State of California, and , (hereinafter designated as "Principal") have entered into a Subdivision Improvement Agreement dated , 20�("Agreement"), the terms and conditions of which are inoorporated herein by reference, whe�eby Principal agrees to install and complete certain designated public improvements for the following project: �project name to be inserted] WHEREAS, under the terms of the Agreement, the Principal is required before entering upon the performance of the work, to file a good and sufficient payment bond with the the City to secure the claims to which referencs is made in Title 3 (commencing with Section 9000) of Part 6 of Division 4 of the Civil Code of the State ofi California. NOW, THEREFORE, we, the Principal and , organized and existing under the laws of the State of , and duly licensed to trans surety business in the State of California, and authorized to execute bonds and undertaking as sole surety, as Surety, are held firmly bound unto the City and all contractors, subcontractors, laborers, materialmen, and other persons employed in the performance of the agreement and referred to in Title 3 (commencing with Section 9000) of Part 6 of Division 4 of the Civil Code of the State of California in the sum of Dollars ($ ), for materials furnished or labor thereon of any kind, or for amounts due under the Unemployment Insurance Act with respect to this work or labor, that the surety will pay the same in an amount not exceeding the amount hereinabove set forth, and also in case suit is brought upon this bond, will pay, in addition to the face amount thereof, casts and reasonable expenses and fees, including reasonable attorney's fees, incurred by City in successfully enforcing this obligation, to be awarded and fixed by the court, and to be taxed as costs and to be included in the judgment therein rendered. It is hereby expressly stipulated and agreed that this bond shall inure to the benefit of any and all persons, companies, and corporations entitled to file claims under Title 3 (cammencing with Section 9000)of Part 6 of Division 4 of the Civil Code of the State of California, so as to give a right of action to them or their assignees in suit brought upon this bond. Should the condition of this bond be fully performed, then this obligation shall become null and void,otherwise it shall be and remain in full force and effect. This bond is executed and�led to comply with the provisions of the act of the Legislature of the State of California as designated in Civil Code Sections 9550-9566, inclusive, and all amendments thereto. The Surety hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Agreement or to the work to be performed thereunder or the REV:02-20-15 VR Page 18 of21 ATTY/AGR.2015.034/SunCap Redwood LLC(IA)