|
Bond No. 070021027
<br /> Premium included in charge
<br /> PAYMENT BOND for performance bond
<br /> KNOW ALL MEN BY THESE PRESENTS: That we, Condon-Johnson &Associates, Inc.
<br /> as Principal, and, Libertv Mutual Insurance Companv ____ organized and
<br /> existing under the laws of the State of �di�os�ia
<br /> Massachusetts , and authorized to execute
<br /> bonds and undertaking as sole surety, as Surety, are held and firmly bound unto any and all
<br /> persons named in California Civil Code Section 3181 whose claim has not been paid by the
<br /> Contractor, company or corporation in the aggregate total of
<br /> Three Hundred Seventy Four Thousand Nine Hundred * Dollars ($ 374,964.00''"**"***'***) (being
<br /> 100% of the Contract amount)for the payment whereof, well and truly to be made, said Principal
<br /> and Surety bond themselves, their heirs, administrators, successors, and assigns, jointly and
<br /> severally, firmly by these presents. •Sixty Four and no/100ths
<br /> THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that, whereas the above with
<br /> the City of Redwood City ("City")to do the faifowing work, to-wit:
<br /> STULSAFT PARK RETAINING WALL PROJECT
<br /> NOW, THEREFORE, if the above-bounden Principal or his subcontra�tors fail to pay any of the
<br /> persons named in Section 3181 of the Civil Code of the State of California, or amounts due
<br /> under the Unemployment Insurance Code with respect to work or labor performed under the
<br /> Contract, or for any amounts required to be deducted, withheld, and paid over to the
<br /> Employment Development Department from the wages of employees of the Contractor and his
<br /> subcontractor pursuant to Section 13020 of the Unemployment Insurance Code of the State of
<br /> California, with respect to such work and labor, the surety will pay for the same, in the amount
<br /> not exceeding the sum specified in this bond, and also, in case suit is brought upon this bond, a
<br /> reasonable attorney's fee, to be fixed by the Court.
<br /> This bond shall inure to the benefit of any person named in Section 3181 of the Civil Code of the
<br /> State of Califomia so as to give a right of action to them or their assignees in suit brought upon
<br /> this bond.
<br /> This bond is executed and filed to comply with the provisions of the act of the �egislature of the
<br /> State of Califomia as designated in Civil Code Sections 3247-3252, inclusive, and all
<br /> amendments thereto.
<br /> And the said Surety, for value received, hereby stipulates and agrees to waive the provisions of
<br /> California Civil Code Section 2819 regarding consent to change, extension of time alteration, or
<br /> addition to the terms of the Contract, or to the work to be performed thereunder, or the
<br /> Specifications accompanying the same, shaEl in any way affect its obligations on this bond; and
<br /> it does hereby waive notice af any such change, extension of time, alteration, or addition to the
<br /> terms of the Contract, or to the work, or to the Specifications.
<br /> IN WITNESS WHEREOF, the above bounden parties have executed this instrument under their
<br /> seals this 1st day of September ,2015 the name and corporate seal of
<br /> STULSAFT PARK RETAINING WALL PROJECT
<br />
|