Agmt90 DDA Sequoia Station - Laserfiche WebLink

Browse Search

JAH:djm 03/06/90R (REDEV) JAH:djm 03/19/90R JAH:djm 04/04/90R extension of time for any such cause shall be for the period of the enforced delay (taking into account reasonable startup and remobilization time) and shall commence to run from the time of the commencement of the cause if notice by the party claiming such extension is sent to the other party within thirty (30) days of the commencement of the cause. If notice by the party claiming an extension is sent to the other party more than thirty (30) days after the commencement of the cause, the extension period shall commence to run only thirty (30) days prior to the giving of such notice. Times of performance under this Agreement may also be extended in writing by the mutual agreement of the Agency and the Developer. §905 Inspection of Books and Records The Agency has the right at all reasonable times to inspect the books and records of the Developer pertaining to the Project Site as pertinent to the purposes of this Agreement. The Developer also has the right at all reasonable times to inspect all public records of the Agency pertaining to the Project Site as pertinent to the purposes of this Agreement. Article 10. DEFAULTS AND REMEDIES §1001 Defaults -- General Subject to the extensions of time set forth in Section 904 of this Agreement, material failure or material delay by either party in performing or complying with any material term or material provision of this Agreement will constitute a default under this Agreement ("Default"). Either party hereto claiming a Default (claimant) shall give written notice of Default to the other party, specifying the Default complained of. For purposes of this Agreement, the term "Default" does not include a default of the kind described in Section 518 of this Agreement. Except as otherwise expressly provided in Sections 517, 1007 and 1008 of this Agreement, the claimant shall not institute proceedings against the other party if the other party within thirty (30) days from receipt of such notice with respect to any Default which may be cured by the payment of money, cures such Default by the payment of all sums due, or within sixty (60) days of such notice with respect to any nonmonetary Default immediately, with due diligence, commences to cure, correct or remedy such failure or delay and shall diligently thereafter pursue such cure, correction or remedy to completion. §1002 Institution of Legal Actions In addition to any other rights or remedies, either party may institute legal action to cure, correct or remedy any Default, to recover damages for any Default, or to obtain any other remedy consistent with the purpose of this Agreement. Such 35