Reso25 16348 - Laserfiche WebLink

Browse Search

21428629.4 3.09. Completion of WSIP San Francisco will complete construction of the physical facilities in the WSIP by June 30, 2032. The SFPUC agrees to provide for full public review and comment by local and state interests of any proposed changes that delay previously adopted project completion dates or that delete projects. The SFPUC shall meet and consult with BAWSCA before proposing to the Commission any changes in the scope of WSIP projects which reduce their capacity or ability to achieve adopted Level of Service Goals and Objectives. The SFPUC retains discretion to determine whether to approve the physical facilities in the WSIP until after it completes the CEQA process as set forth in Section 4.07. 9.07. City of Brisbane, Guadalupe Valley Municipal Improvement District, Town of Hillsborough A. The parties acknowledge that San Francisco has heretofore provided certain quantities of water to the City of Brisbane (“Brisbane”), Guadalupe Valley Municipal Improvement District (“Guadalupe”) and the Town of Hillsborough (“Hillsborough”) at specified rates or without charge pursuant to obligations arising out of agreements between the predecessors of San Francisco and these parties, which agreements are referred to in judicial orders, resolutions of the SFPUC and/or the 1960 contracts between San Francisco and Brisbane, Guadalupe and Hillsborough. The parties intend to continue those arrangements and accordingly agree as follows: 1. Nothing in this Agreement is intended to alter, amend or modify the terms of SFPUC Resolution No. 74-0053 or the indenture of July 18, 1908 between the Guadalupe Development Company and the Spring Valley Water Company. 2. Nothing in this Agreement is intended to alter, amend or modify the Findings of Fact and Conclusions of Law and Judgment dated May 25, 1961 in that certain action entitled City and County of San Francisco v. Town of Hillsborough in the Superior Court of the State of California in and for the County of Marin, No. 23282, as modified by the Satisfaction of Judgment filed October 23, 1961 and the Compromise and Release between Hillsborough and San Francisco dated August 22, 1961. The rights and obligations of Hillsborough under these documents shall continue as therein set forth. 3. Nothing in this Agreement is intended to affect or prejudice any claims, rights or remedies of Guadalupe or of Crocker Estate Company, a corporation, or of Crocker ATTY/RESO.0091/CC RESO AMENDING 2021 AMENDED AND RESTATED WATER SUPPLY AGREEMENT - EXHIBIT A REV: 08-18-25 MI Page 22 of 34