|
Bond#024048968
<br /> Premium included in the
<br /> Performance Bond
<br /> PAYMENT BOND
<br /> KNOW ALL MEN BY THESE PRESENTS: That we, a�ocka Construction,�nc.
<br /> 4455 Enterprise St. Fremont,CA 94538
<br /> as Principal, and, Liberty Mutual Insurance Company OPgaI11Z@CI aI1CI
<br /> existir�g under thQ !�ws of the State �f C�#�� _ .� ,
<br /> MA , and authorized to execute
<br /> bonds and undertaking as sole surety, as Surety, are held and firmly bound unto any and all
<br /> persons named in California Civil Code Section 3181 whose claim has not been paid by the
<br /> Contractor, company or corporation in the aggregate total of
<br /> Three Hundred Thirty-Nine Thousand Five Hundred and no/100------ DOIIaI'S �� 339,soo.00-------� (being
<br /> 100% of the Contract amount) for the payment whereof, well and truly to be made, said
<br /> Principal and Surety bond themselves, their heirs, administrators, successors, and assigns,
<br /> jointly and severally, firmly by these presents.
<br /> THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that, whereas the above with
<br /> the City of Redwood City ("City") to do the following work, to-wit:
<br /> SANITARY SEWER PUMP STATION 101MPROVEMENTS PROJECT
<br /> NOW, THEREFORE, if the above-bounden Principal or his subcontractors fail to pay any of the
<br /> persons named in Section 3181 of the Civil Code of the State of California, or amounts due
<br /> under the Unemployment Insurance Code with respect to work or labor pertormed under the
<br /> Contract, or for any amounts required to be deducted, withheld, and paid over to the
<br /> Employment Development Department from the wages of employees of the Contractor and his
<br /> subcontractor pursuant to Section 13020 of the Unemployment Insurance Code of the State of
<br /> California, with respect to such work and labor, the surety will pay for the same, in the amount �
<br /> not exceeding the sum specified in this bond, and also, in case suit is brought upon this bond, a
<br /> reasonable attorney's fee, to be fixed by the Court.
<br /> This bond shall inure to the benefit of any person named in Section 3181 of the Civil Code of the
<br /> State of California so as to give a right of action to them or their assignees in suit brought upon
<br /> this bond.
<br /> This bond is executed and filed to comply with the provisions of the act of the Legislature of the
<br /> State of California as designated in Civil Code Sections 3247-3252, inclusive, and all
<br /> amendments thereto.
<br /> And the said Surety, for value received, hereby stipulates and agrees to waive the provisions of
<br /> California Civil Code Section 2819 regarding consent to change, extension of time alteration, or
<br /> addition to the terms of the Contract, or to the work to be performed thereunder, or the
<br /> Specifications accompanying fhe same, shall in any way affect its obligations on this bond; and
<br /> it does hereby waive notice of any such change, extension of time, alteration, or addition to the
<br /> terms of the Contract, or to the work, or to the Specifications.
<br /> SANITARY SEWER PUMP STATION 10
<br /> IMPROVEMENTS PROJECT
<br />
|