AgdaPkt 2013-07-22 - Laserfiche WebLink

Browse Search

7.A. - Page 160 (c) Obtain City sign-off on the final building permit and other Approvals for the completed Project such that Developer shall be entitled to be issued a Certificate of Completion as set forth in Section 4.13 of this Agreement; and (d) After commencement of the work of improvement of the Proj ect, the Developer shall not permit the work of construction of the Proj ect to cease or be suspended for a time period in excess of sixty (60) calendar days (excluding weekends and holidays), either consecutively or in the aggregate, other than as a result of an Unavoidable Delay. The City Manager, in his or her discretion, which shall not be unreasonably withheld, may extend the Project Completion Date for up to an additional one hundred twenty (120) days, in the aggregate. 4.7 Compliance with Laws. All work performed in connection with the construction or installation of the Project shall comply with all applicable Laws and Approvals. 4.8 Performance Schedule. All planning construction, installation and other development obligations and responsibilities of the Developer and/or the City related to the Project shall be initiated and completed within the times specified in the Performance Schedule (Exhibit D), or within such reasonable extensions of such times granted by the City Manager or as otherwise provided for in this Agreement. 4.9 Developer Attendance at City Meetings. The Developer agrees to have one or more of its employees or consultants who are knowledgeable regarding this Agreement and the development of the Proj ect, such that such Person(s) can meaningfully respond to City staff questions regarding the progress of the Project, attend meetings with City staff or meetings of the City governing body, when requested to do so by City staff, with reasonable advance written Notice to the Developer. 4.10 City Right to Inspect Project and Site. During periods of construction or installation of the Proj ect, the City shall perform weekly inspections of the Proj ect and the Site, on a schedule agreeable to both the City and Developer; provided, however, the Parties may mutually agree on adjustments to the inspection schedule as necessary in order to meet Developer's construction schedule. In order to perform such inspections, the City shall have the right of reasonable access to the Site, without the payment of charges or fees, during normal construction hours and upon reasonable advance notice. Any and all City representatives who enter the Site shall identify themselves at the construction management office or, if none, to the apparent on-site construction supervisor on the Site, upon their entrance onto the Site, and shall at all times be accompanied by a representative of the Developer, while on the Site. The Developer shall make a representative of the Developer available for this purpose at all times during normal construction hours, upon reasonable advance Notice from the City. The City shall indemnify and hold the Developer harmless from injury, property damage or liability to the extent arising out of the exercise by the City of the right of access to the Site provided in this Section 4.10, except to the extent that any such injury, property damage or liability arises from the negligence or willful misconduct of any of the Developer Parties. If in the City's reasonable judgment it is necessary, the City shall have the further right, from time to time, at its own cost, to retain a consultant or consultants to inspect the Proj ect and verify compliance by the Developer with the provisions of this Agreement. The Developer acknowledges and agrees that 82483.00009\7571312.11 32 ATTY/AGR/2013.118/BLOCK 2 HUNTER STORM REV: 07-19-13 PT