Agmt13 Southland Construction - Laserfiche WebLink

Browse Search

Protection of Propertv/Public Safetv Contractor agrees to comply with the following when completing Scope of Work and Services: 1- Confine operations at site to areas permitted by contract documents. 2- Do not encumber site with excessive material or equipment. 3- Do not impose any load on any structure that will damage or endanger structure. 4- Take precautions necessary to prevent annoyance to occupants adjacent to or in the vicinity of the work. 5- Contractor is solely responsible for conditions of the job site, including safety of all persons and property during performance of Services. This requirement will apply continuously and will not be limited to normal working hours. Safety and sanitary provisions shall conform to applicable Federal, State, County, and local laws, regulations, ordinances, standards, and codes. Where any of these are in conflict the more stringent requirement shall be followed. All public and private property, shall be safely guarded from injury or loss in connection with this contract by the Contractor at all times. Should any facility, structure, ar property be damaged during operations of the Contractor, he/she shall immediately notify the proper owner or authorities. 6- The Contractor at his/her expense, shall rebuild, repair, restore, and make good to the City's satisfaction all injuries and damages resulting from his/her operations. 7- During performance of the Services, the Contractar shall erect and maintain necessary temporary fences, bridges, lights, barriers, or other safeguards (at Contractor's expense) as shall be appropriate under the circumstances in his/her judgment for the prevention of accidents; and he/she shall take other precautions as necessary for public safety. Liquidated Damages City and Contractor recognize that time is of the essence for completion of Services in this Agreement and it is agreed that a delay will result in damage sustained by the City, and that it is and will be impracticable and extremely difficult to ascertain and determine the actual damage which City will sustain in the event of and by reason of such delay. Accordingly, City and Contractor agree that Contractor shall pay City [$2,500.00] for each calendar day after the deadline specified for completion of all tasks within the Scope of Services listed in E�chibit A (Scope of Services). The City may deduct any accrued liquidated damages from any monies payable to Contractor on account of services performed by Contractor. Liquidated damages for delay shall only cover and be in lieu of the actual damages suffered by City as a result of delay referenced above. Liquidated damages shall not cover the cost of completion of the work, damages resulting from defective work, cost of temporary replacement facilities, damages suffered by others who then seek to recover their damages from City (for example, delay claims of other contractors or subcontractors), and defense costs thereof. Page 16 of 19