Res12 P-2165 - Laserfiche WebLink

Browse Search

C�0 G°�� The Port of Redwood City reserves the right to waive minor irregularities and omissions in the information contained in the pre-qualification application submitted, to make all final determinations, and to determine at any time that the pre-qualification procedures will not be applied to the Wharves 1 and 2 Project. Pre-qualifications aze due to be received by Port of Redwood City, at 675 Seaport Blvd., Redwood City, CA, 94063 by 5:00 PM PDT, Mazch 16, 2012. Contractors may submit pre- qualification packages during regular working hours on any day that the offices of the Port of Redwood City are open. The Port of Redwood City may refuse to grant pre-qualification where the requested information and materials aze not provided, or not pmvided by Mazch 16, 2012. There is no appeal from a refusal for an incomplete or late applicarion. The closing time for bids will not be changed in order to accommodate supplementarion of incomplete submissions, or late submissions. Where a timely and completed applicarion results in a rating below that necessary to pre-qualify, an appeal can be made. An appeal is begun by the Contractor delivering notice to the Port of Redwood City of its appeal of the decision with respect to its pre-qualification rating, within five (5) calendaz days of the date of mailing or delivery (personally or via facsimile) of the Port's rating determination. Without a rimely appeal, the Contractor waives any and all rights to challenge the decision of the Port of Redwood City, whether by administrative process, judicial process or any other legal process or proceeding. The Port will provide the appellant a Notification of the basis for the disqualification and any supporting evidence that has been received from others or adduced as a result of an investigarion by the Port. The Norification will state the Appellant will have the oppommity to be heard before the Appeals Panel (delegated by the Port of Redwood City Board of Commissioners) within three (3) calendaz days from the date of delivery or mailing of the Notification. The Contractor will be given the opportunity to present information and present reasons in opposition to the rating. Within one day after the conclusion of the hearing, the Appeals Panel will render its decision. It is the intention of Port of Redwood City that the date for the submission and opening of bids will not be delayed or postponed to allow for completion of an appeal process. Note: A Contractor may be found not pre-qualified for bidding on The Wharves 1 and 2 Replacement Project contract to be let by the Port of Redwood City. In addition, a Contractor may be found not pre-qualified for either: (1) Omission of requested information or (2) Falsification of information The Port of Redwood City shall have no obligarion to any Respondent to tlris RFQ unless and until the Port awards a contract. The Port reserves the right to reject any or all responses to this RFQ and subsequent bids for any reason or no reason. There is no guazantee the Port will issue any notice to proceed and the Port may terminate at any time any agreement, pursuant to the termination clause in the agreement, entered into as a result of ttris procurement process. paqe a a a �y, � l/